Welcome to Cheap Carpet Los Angeles ("Company", "we", "our", or "us"). These Terms and Conditions ("Terms") govern your use of our website located at ("Site") and our services, including carpet sales, installation, removal, and related flooring services (collectively, the "Services").
By accessing or using our Site and Services, you agree to be bound by these Terms. If you do not agree with any part of these Terms, you should not access the Site or use our Services.
You must be at least 18 years of age to use our Services. By agreeing to these Terms, you represent and warrant that:
Cheap Carpet Los Angeles provides a variety of carpet-related services, including:
We reserve the right to modify or discontinue any aspect of our Services at any time without notice.
All quotes provided are estimates based on the information available at the time of inquiry. Final pricing may vary based on:
Quotes are valid for 30 days unless otherwise stated.
Note: While we strive to maintain accurate pricing, typographical errors or pricing inaccuracies may occur. We reserve the right to correct any errors and cancel or refuse orders that were inaccurately quoted.
To confirm a service appointment or material order, we may require a deposit. Deposits are typically non-refundable unless otherwise specified in writing. Orders will not be scheduled or processed until the deposit is received.
You are responsible for ensuring all specifications (e.g., carpet type, color, room dimensions) are accurate before the order is finalized.
The customer is responsible for preparing the installation site. This includes:
If additional labor is required due to unprepared spaces, additional charges may apply.
You agree to provide safe and reasonable access to your property during the scheduled installation window. If access is denied or delayed, rescheduling fees may be applied.
If installers encounter subfloor damage, mold, or other hazards, the project may be paused until the issue is resolved. We are not responsible for delays caused by such conditions.
You may cancel or reschedule a service by contacting us at least 48 hours before the scheduled appointment. Late cancellations may result in forfeiture of your deposit.
Cheap Carpet Los Angeles reserves the right to cancel or reschedule services due to weather, illness, emergencies, or availability of materials.
We stand behind the quality of our products and services. However, due to the nature of custom flooring:
Contact us immediately if you experience an issue with your product or service.
Most carpet products include a manufacturer warranty that covers material defects under normal residential or commercial use. Warranty length and terms vary by product.
Installation Warranty: We offer a 1-year workmanship warranty on all installations unless otherwise noted. This covers issues arising from improper installation, not wear and tear or misuse.
Note: Warranty is void if flooring is improperly maintained, exposed to moisture, or altered after installation.
All content on our website—including logos, text, images, designs, and software—is the property of Cheap Carpet Los Angeles or its licensors and is protected by copyright and trademark laws.
You may not:
By using our Site and Services, you agree:
Violation of these rules may result in suspension or termination of access to our Services.
To the fullest extent permitted by law, Cheap Carpet Los Angeles and its affiliates shall not be liable for any:
Our total liability for any claim related to Services shall not exceed the total amount paid by you for those Services.
You agree to indemnify and hold harmless Cheap Carpet Los Angeles, its owners, employees, contractors, and partners from any claims, liabilities, damages, or expenses arising out of:
Our Site may contain links to third-party websites or services. We are not responsible for the content, accuracy, or practices of any third-party sites. Access them at your own risk.
We are committed to protecting your privacy. Our Privacy Policy governs how we collect, use, and safeguard your personal information. By using our Site, you consent to our data practices outlined in the Privacy Policy.
Cheap Carpet Los Angeles shall not be held liable for any delay or failure to perform resulting from causes beyond our reasonable control, including:
These Terms are governed by the laws of the State of California, without regard to conflict of law principles. Any disputes arising from these Terms shall be resolved in the courts located in Los Angeles County, California.
In the event of a dispute, both parties agree to attempt to resolve the matter informally before pursuing legal action. If the dispute cannot be resolved within 30 days, it may be submitted to binding arbitration in accordance with California law.
We reserve the right to update or modify these Terms at any time. When changes are made, we will update the "Last Updated" date at the top of this page. Continued use of our Site and Services after any changes means you accept the revised Terms.
Thank you for choosing Cheap Carpet Los Angeles. We appreciate your business and look forward to serving your flooring needs with honesty, affordability, and quality.